Explorez tous les épisodes du podcast Chicks in Construction
| Titre | Date | Durée | |
|---|---|---|---|
| Flipped Homes, Hidden Damage & the Truth About "As-Is" Sales | 28 Jul 2026 | 01:02:35 | |
Welcome back to another episode of Chicks in Construction — the true crime podcast, construction edition! This week Mikki and Jessica kick things off with some Chicky Chat: Hector's international gallbladder surgery adventure in El Salvador (complete with translation app fails, gloveless procedures, and Juan Carlos saving the day), plus travel tales from Jess's European cruise. Then it's on to the main story: why the prettiest flipped homes can hide the ugliest secrets. Fresh paint, brand-new floors, and gorgeous quartz countertops can conceal water damage, mold, missing permits, and structural problems that don't show up until months after closing. As always, we're not attorneys or doctors, and this isn't legal advice — but these real cases and lessons can help you avoid becoming one of our future stories. Got a story of your own? Share it with us at chicksinconstruction.com — we'll always keep you anonymous, even if you don't check the box. Follow us: Facebook, LinkedIn & Instagram: @chicksinconstructionpodcast TikTok: @chicksinconstruction #ChicksInConstruction #HomeBuying #HouseFlipping #RealEstate #TrueCrimePodcast #HomeInspection #RenovationRedFlags Chapters: Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| What Homeowners Insurance Actually Covers | 21 Jul 2026 | 00:54:03 | |
In this episode of Chicks in Construction, Mikki Paradis and Jessica Abreu explain what homeowners insurance actually covers, why construction defects and long-term water intrusion are frequently excluded, and how homeowners can protect themselves before something goes wrong. They also discuss the surprisingly low barrier to becoming a licensed general contractor, the difference between a home inspector and a building inspector, and why a contractor can be responsible for an entire home without completing the apprenticeship or experience requirements expected in many individual trades. Through real court disputes, homeowner stories, and firsthand experiences, Mikki and Jessica explain why insurance is not a home warranty, contractor warranty, or maintenance plan—and why identifying the cause of damage is often more important than proving the damage exists. You’ll also learn what documents to save, when filing a claim may increase your future costs, what to do after a denial, and why hiring the cheapest contractor can become the most expensive decision you ever make. 00:00 – General contractor licensing | |||
| What Every Homeowner Should Know About Plumbing | 14 Jul 2026 | 00:58:55 | |
Main Street Plumbing Company: Main Street Plumbing Number: Capps Plumbing Company: In this episode of Chicks in Construction, Mikki Paradise welcomes Hailey, a plumber with more than 14 years of experience, to share hilarious stories, hard-earned lessons, and practical advice every homeowner should know. From the strangest things ever flushed down toilets to why plumbers cringe when they hear someone used Drano, Hailey explains the mistakes that lead to expensive repairs—and how homeowners can avoid them. The conversation also explores what it's like being a woman in the plumbing trade, dealing with stereotypes, earning respect on the job, and why the construction industry needs more women. Along the way, Mikki and Hailey discuss water heaters, water pressure, plumbing maintenance, DIY repairs, builder shortcuts, and the importance of finding a plumber you can trust. Whether you're a homeowner trying to prevent costly repairs or someone considering a career in the skilled trades, this episode is packed with practical advice, laughs, and insider knowledge. 00:00 – Welcome back to Chicks in Construction 01:00 – Meet guest plumber Hailey 04:00 – How Hailey became a plumber 06:30 – Why the trades were a better fit than college 07:00 – What it's like being a woman in plumbing 10:00 – Why construction should be called "male-populated," not "male-dominated" 11:30 – Homeowner mistakes plumbers see every day 14:00 – Why plumbers hate Drano and drain cleaners 17:00 – The only three things that belong in a toilet 18:00 – Flushable wipes aren't really flushable 19:00 – Grease, clogged drains, and expensive repairs 20:00 – The strangest things ever flushed down a toilet 23:00 – Inside Main Street Plumbing 26:00 – Why water pressure matters 28:00 – Knowing where your main water shutoff is 30:00 – Water damage prevention every homeowner should know 33:00 – Should you flush your water heater? 35:00 – Plumbing maintenance plans explained 37:00 – Extending the life of your water heater 38:00 – Warning signs your water heater is failing 39:00 – Why you should shut your water off before vacation 42:00 – Cheap toilets vs. quality plumbing fixtures 45:00 – Why trustworthy contractors are worth keeping 50:00 – Builder shortcuts plumbers see every day 53:00 – Which plumbing repairs are safe to DIY? 55:00 – Final homeowner tips | |||
| Contractor Catastrophes: What Every Homeowner Should Know | 07 Jul 2026 | 00:59:35 | |
In this episode of Chicks in Construction, hosts Mikki Paradis and Jessica Abreu discuss an Arizona case in which senior citizens Elizabeth Matthews and her husband hired Settlers West Home Builder in May 2022 to build a $1M custom home in Tucson’s Catalina Foothills, then were persuaded to sign a separate $300,000 guest-house contract and pay large amounts in cash outside their construction loan. After paying $150,000 for the main project plus $150,000 and later $105,000 toward the guest house (and nearly $60,000 in upgrades), the couple saw major delays, received no refund when requested, and ultimately learned the builder filed for bankruptcy in December 2023, leaving two homes only framed. The builders had 18 license complaints before revocation in February 2024. The hosts stress red flags, not paying for uncompleted work, milestone-based draws, lien waivers, and retainage. 00:00 Renovation Limbo Warning 00:25 Podcast Intro and Horror Stories 02:47 Why Contractors Dodge Consequences 09:04 Time Optimist Tangent 13:45 Hoarding vs Throwing Away 19:01 Deep Dive Redemption Setup 20:34 Dream Home Disaster Begins 22:59 Meet the Matthews and the Contract 26:08 Guest House Upsell Red Flags 27:53 Discounts as Red Flags 28:42 Cash Pressure and Markups 31:02 Selling the House to Pay 32:54 Delays and Sunk Cost Trap 36:34 Overpaying for Bare Framing 38:38 Complaints and Bankruptcy Twist 48:13 Why Fixing Work Costs More 52:39 Pay Milestones and Lien Waivers 56:43 Retainage and Final Takeaways | |||
| The House That Shouldn’t Have Been Demolished | 30 Jun 2026 | 00:39:38 | |
Mikki Paradis and co-host Jessica Abreu introduce the Chicks in Construction podcast, explaining their mission to help homeowners understand what’s normal, spot red flags, and avoid contractor scams by sharing “Homeowner Horror Stories” submitted at chicksinconstruction.com. They discuss how construction failures often come from chained mistakes and share a shocking Atlanta, Georgia incident where a private demolition crew tore down the wrong inherited family home while the owner was on vacation, then left; the City of Atlanta issued a correction notice requiring the owner to clean up rubble and warning of fines despite the work being unpermitted and unauthorized. They note similar Atlanta cases, compare homeowner protections across states, and invite listeners to submit stories and follow the show on social media. 00:00 Cold Open Banter 00:20 Podcast Mission 03:14 Submitting Horror Stories 05:16 Cups Hydration Heat 05:54 NC Weather Whiplash 07:44 Running Zombies Alaska 12:51 Neighborhood Demo Problem 15:40 Why Trees Matter 16:33 House Shouldnt Demolish 18:13 Wrong House Shock 19:51 How Crews Miss Addresses 21:02 Drywall Wrong House Story 23:16 Safeguards That Failed 23:48 Irreplaceable Memories Lost 25:59 Contractor City Fallout 29:04 Atlanta Pattern Of Demos 35:13 Homeowner Protections Gap 39:22 Share Your Story Outro | |||
| Contractor Collapse: How Homeowners Can Protect Themselves | 23 Jun 2026 | 00:59:32 | |
On this episode of The Chicks in Construction, hosts Mikki Paradis and Jessica Abreu discuss how scammers exploit stress and access to personal information, including a story of a woman in the Raleigh area who was tricked by a caller ID–spoofed “Wake County Sheriff’s Office” into paying $4,000 to “buy out” a fake warrant. They explain why law enforcement doesn’t collect payments over the phone and advise hanging up and calling the non-emergency number directly. The conversation then shifts to an Arizona luxury pool contractor situation where homeowners paid large deposits for $80,000–$200,000 backyard projects that stalled, leaving unsafe excavation pits and unfinished work. They outline red flags like massive upfront deposits, loss of momentum, vague delays, and misleading social media, and recommend protections such as milestone-based payments, verifying suppliers, checking licensing/standing, and cutting losses early. 00:00 Contractor Scam Reality Check 00:31 Meet The Hosts And Mission 01:27 Jury Duty Sheriff Scam 04:37 Dark Web And Number Cloning 09:04 How The Scam Extracts Money 12:40 Aftermath And Safety Tips 20:22 Share Your Horror Stories 21:51 Arizona Luxury Pool Nightmare 25:52 Deposits Paid Then The Collapse 27:43 Pool Build Nightmare 28:43 Cashflow Collapse Explained 30:44 Upfront Deposit Red Flags 33:15 Permits Inspections Pushback 37:06 Branding Can Be Fake 40:06 Momentum Stalls and Demo Trap 45:17 No Crew Means No Pay 48:05 Protect Yourself With Milestones 51:43 References Research and Reality 56:09 Final Lessons and Call In | |||
| Nailed It? The Hard Truth About Home Makeovers | 16 Jun 2026 | 00:56:40 | |
In this episode of Chicks in Construction, Mikki and Jessica unpack another homeowner renovation nightmare — this time from Florida — involving an unlicensed contractor, endless delays, disappearing cabinets, surprise costs, and complete chaos inside a family home for nearly eight months. What started as an exciting kitchen renovation quickly spiraled into stress, financial anxiety, strangers showing up unannounced, and a growing realization that the contractor they trusted was never legitimate in the first place. Along the way, Mikki and Jessica go on several hilarious side quests involving jury duty scams, true crime energy, sketchy contractors, and why homeowners must verify licenses, insurance, permits, and registrations before any renovation begins. The episode is equal parts comedy, cautionary tale, and practical education for homeowners trying to avoid becoming the next construction horror story. 00:00 – The emotional reality of living through a renovation nightmare | |||
| Urgency, Fear, and Fraud: How to Spot a Shady Contractor | 09 Jun 2026 | 00:55:21 | |
Hosts Mikki Paradis and Jessica Abreu discuss Bay Area reports of groups posing as contractors who target homeowners—especially elderly people—by showing up unsolicited, claiming urgent dangers like failing roofs or unsafe chimneys, and using fear to force quick decisions. They describe how scams often start with small quotes that rapidly escalate into tens or hundreds of thousands of dollars, including one reported $450,000 loss, and note these groups may operate across counties and states under frequently changing business names. The episode highlights red flags such as high-pressure urgency, shifting company identities, and sudden cost increases, and offers protections: never sign the same day, get multiple opinions/inspections, verify licenses and business registration via the Secretary of State, check addresses and phone numbers, and research local permit/inspection requirements. They invite viewers to submit stories at chicksinconstruction.com and share where to follow the podcast on social media. 00:00 Contractor Scam Cold Open 00:28 Meet the Hosts 02:04 Spicy Comments and Rage Bait 04:25 Inspection Rework Rule 08:23 Blocking Trolls and Staying Busy 10:41 Rental Setup Chaos 13:48 Special Trash Trim Haul 17:49 Send Us Your Stories 19:44 Traveling Contractor Scams 20:51 Door Knock Panic Pitch 23:57 Bay Area Scam Details 26:09 Scammers Look the Part 26:37 Fear Based Pitch 27:48 Pressure Sales Red Flags 30:22 Elderly Targeted Scam 32:26 Costs Spiral Fast 34:32 Rotating Company Names 37:13 Door to Door Reality 39:03 Verify People Not Brands 42:50 Organized Scam Networks 45:18 Common Red Flags List 50:16 Protect Yourself Checklist 53:30 Wrap Up And Share | |||
| Remodel Horror Stories & Contractor Secrets with Erika Zimandy | 02 Jun 2026 | 00:58:29 | |
In this episode of Chicks in Construction, Mikki and Jessica sit down with licensed general contractor and real estate investor Erika Zimandy of Hilltop GC for an honest conversation about what homeowners really need to know before hiring a contractor. Erika shares her journey from public health into real estate investing and construction, offering a unique perspective from both sides of the renovation world — as both a homeowner/investor and a licensed GC. Together, they unpack contractor red flags, remodeling horror stories, pricing differences between bids, realistic timelines, deposits, permits, inspections, and the biggest myths HGTV has taught homeowners. The episode also dives into the controversial topic of contractors charging homeowners for failed inspections, whether homeowners should buy their own materials, and what upgrades actually provide the best return on investment. If you’re planning a remodel or simply want to avoid expensive construction mistakes, this episode is packed with practical advice and real talk from women working in the construction industry. 00:00 – Introduction to Erika Salgado-Zemandi from Hilltop GC | |||
| Contractor Horror Story: The Countertop Nightmare | 26 May 2026 | 00:48:23 | |
In this episode of Chicks in Construction, Mikki and Jessica dive into one of the hottest debates in the construction world right now: who should pay when a contractor fails an inspection? Mikki shares a wild personal story involving a fence contractor, disappearing work crews, and an explosive confrontation that proves shady contractors can target anyone — even experienced construction professionals. The conversation then shifts into a homeowner horror story from Connecticut involving a simple countertop replacement that spirals into a four-month nightmare involving delays, disappearing contractors, leaking sinks, surprise charges, and an unlicensed handyman posing as a legitimate contractor. Along the way, the hosts unpack contractor licensing, inspection failures, how homeowners can protect themselves, and why doing even a little research before a remodel can save thousands of dollars and endless frustration. This episode is equal parts hilarious, educational, and cautionary tale for every homeowner considering a renovation project. 00:00 – Mikki’s opening rant about failed inspections and contractor responsibility Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Unmasking Construction Scams: Homeowner Stories | 19 May 2026 | 00:54:34 | |
Mikki Paradis and Jessica Abreu host an episode of Chicks in Construction about recurring homeowner scams where contractors fail inspections and try to charge homeowners to fix their own mistakes. They share a South Carolina story in which a homeowner hires “Travis” from Facebook to convert two closets into a half bath for $12,000 in three weeks, pays a $4,000 deposit, then gets hit with extra charges after failed plumbing and electrical inspections, including $1,500 and $800 fixes. After five weeks and $6,500 spent, the homeowner discovers Travis isn’t licensed, can’t provide receipts, and abandons the job. A licensed contractor finishes for $4,500, bringing the total to over $18,000 and four months. They emphasize verifying local requirements, licenses, and insurance, and promote their North Carolina “Pours and Plans” contractor-vetting events. 00:00 Drywall Ethics Cold Open 00:20 Podcast Intro Banter 00:53 Spicy Comment Clapback 02:25 Brain Fog And Tab Chaos 04:29 Vitamin Dealer And Birthdays 07:32 Contractor Scams Explained 13:14 Inspections And Who Pays 19:28 Seniors Panel And Aging Talk 23:03 Horror Story Begins Facebook Hire 24:10 Bathroom Reno Red Flags 27:02 Ask Questions Always 27:36 Confidence Isnt Competence 28:11 Permits And Failed Plumbing 29:13 Paying For Mistakes 32:20 Electrical Code Fail 34:37 New Crews On Site 36:17 Toilet Flange Explained 38:30 License Check Fallout 40:46 Receipts And Ghosting 42:08 Real Contractor Cleanup 43:27 Facebook Referrals Risk 45:22 Pores And Plans Events 51:28 Vet License And Insurance 54:02 Wrap Up And Share Stories | |||
| Building Nightmares: The True Cost of Oversight | 12 May 2026 | 00:51:42 | |
Hosts Mikki Paradis and Jessica Abreu of Chicks in Construction explain why permits matter and share a Denver homeowner horror story: Kevin and Noelle Collins hired Schwab Builders (run by Avi Schwab and involving his father Sean) for a major remodel of their 1950s bungalow, paying over $250,000 in installments. After demolition, progress stalled, communication turned vague, and they later discovered no permits were pulled and the contractor wasn’t properly licensed. A courtesy inspection led to a stop-work order and an engineering report declaring the home unsafe to occupy, forcing the family out after Thanksgiving 2023 and into two years of paying mortgage plus rent. Prosecutors found multiple victims, alleged over $1.1M in consumer fraud, and a jury convicted the builder on 47 felony counts; Avi was sentenced to 10 years. The BBB “Restoring Trust” program helped rebuild the Collins’ home for free, and the hosts highlight red flags like failing to verify licensing and skipping permits. 00:00 Permits Matter 00:13 Welcome and Submit Stories 01:42 Sneeze Talk Tangent 03:50 Tough Mudder Signup 08:59 Camping and Clean Freak 14:30 Back to the Horror Story 18:09 Denver Remodel Nightmare Setup 19:46 Schwab Builders Red Flags 20:55 Quarter Million Renovation Reality 22:22 Contracts and Payments 24:38 Demo and Dependency Trap 27:53 Delays and Ghosting 30:37 No Permits No License 35:30 Lawyer and Courtesy Inspection 37:45 Stop Work Unsafe Home 43:03 More Victims and Fraud 47:21 Trial Verdict and Sentencing 48:56 Restoring Trust and Red Flags 52:00 Final Takeaways and Outro
Follow on Social Media: ________________ Love what you hear? | |||
| Caught in the Act: Shady Contractors and How to Spot Them | 05 May 2026 | 00:59:54 | |
Hosts Mikki Paradis and Jessica Abreu discuss how homeowners can still be scammed by contractors who seem legitimate, stressing that confidence can be a red flag and research is essential. They cover a fraud case in upstate New York (2019–2023) where a couple used multiple similar business names, contracts, and fake references—one was the contractor’s wife—to take large upfront deposits, stall or abandon projects, deliver poor work, refuse refunds, and spend victims’ money on personal expenses like casino trips and luxury vehicles; losses exceeded $1.5 million across more than a dozen homeowners. The husband received a 5–15 year prison sentence and the wife got six months plus probation. They outline protections: verify licenses and qualifiers, research names via Secretary of State and court filings, avoid deposits over 20%, tie payments to progress, don’t rush decisions, and visit active job sites. 00:00 Confidence Is a Red Flag 00:17 Meet the Hosts 00:48 Justice and Jail Jokes 02:55 Hector and the Purchase Order 06:16 Tech Adoption in Trades 08:15 Why Trades Beat AI 09:37 Research and Real Facts 11:23 Scam Story Setup 14:57 Fraud Case Overview 19:57 Multiple Company Names Warning 23:44 Fake References and Reviews 29:04 Verify Work on Site 31:32 Where the Money Went 31:51 Victims Count the Losses 32:15 Charges and Sentencing 33:51 How the Scam Looked Legit 36:03 Red Flags to Watch 36:07 Multiple Business Names Explained 39:49 Upfront Deposits and Overpaying 41:58 Work Stalls and Bad Workmanship 44:44 Protect Yourself With Research 47:58 Verify Licenses and Qualifiers 52:21 Progress Payments Not Pressure 57:17 Final Takeaways and Share Stories
Follow on Social Media: ________________ Love what you hear? | |||
| Shaky Foundations: A Homeowner’s Guide to Contractor Scams | 28 Apr 2026 | 01:01:07 | |
Hosts Mikki Paradis and Jessica Abreu open with a “chicky chat” recap of Mikki babysitting Jess’s kids, including an Uno-cheating incident and the kids texting their parents throughout the night. They then share a homeowner horror story from Sam in South Carolina, who hired a referred contractor to enclose a patio into a sunroom for $42,000 without getting other quotes or verifying a license. After failed inspections, repeated upcharges for rework, delays, and being asked basic planning questions on site, Sam discovered the contractor wasn’t licensed and was allegedly “working under” someone else’s license before ghosting. Sam hired a licensed contractor to redo and finish the project for $28,000 more, stretching the timeline to nearly a year, and the hosts stress that verifying a contractor’s license is the bare minimum step to avoid being scammed. 00:00 Verify That License 00:34 Babysitting Chaos Recap 04:28 Uno Cheating Meltdown 06:58 Kids Texting The Parents 10:21 Dogs Yes Kids No 10:47 Homeowner Horror Stories Setup 13:14 Sam Sunroom Plan Begins 14:27 Contractor Jargon Red Flags 19:36 Deposit And Demo Start 21:45 Footing Inspection Fails 23:08 Inspectors And The Double Dip Scam 30:10 Paying For Rework No Way 30:39 Call the Inspector 31:33 Framing Red Flags 32:05 Failed Header Inspection 35:15 Engineered Beam Upcharge 36:05 Delays and No Shows 39:07 Subs Asking Homeowner 41:40 License Check Discovery 44:39 Confrontation and Ghosting 48:14 Damage Control Strategy 50:34 Hiring a Real Contractor 52:48 Costly Finish and Lessons 54:25 Verify Licenses Always 56:32 Qualifier License Explained 01:01:21 Wrap Up and Share Story
Follow on Social Media: ________________ Love what you hear? | |||
| Beware the Door Knockers: Chuck in a Truck Scam | 21 Apr 2026 | 00:53:49 | |
Mikki Paradis and co-host Jessica Abreu of Chicks in Construction discuss their growing audience, pushback from trolls, and why homeowners should watch comment sections for shady contractors. They revisit a key rule—don’t pay in full until work is complete—and share a homeowner horror story about John O’Brien of “Traditional Masonry and Construction,” accused of running a door-to-door fraud operation from 2021–2024 across multiple states, largely targeting seniors and stealing roughly $1.9–$2.6 million. Using fear-based claims about foundations, chimneys, and structural danger, he took upfront payments, inflated costs (e.g., $9,500 to $80k–$95k), delivered poor or unnecessary work, and disappeared after collecting final payments. They outline major red flags: unsolicited visits, urgent structural warnings, sudden price escalations, large upfront payments, and avoiding independent inspections. 00:00 Payment Rules Upfront 00:21 Show Welcome And Growth 01:03 Trolls And Shady Contractors 05:03 Clapbacks And Vampire Joke 08:16 Gatekeeping Unlicensed Guests 10:55 Horror Story Setup 11:40 Chuck And Truck Scams 13:08 Door Knock Red Flags 17:00 John OBrien Scam Tactics 20:40 Fear Sales And Senior Targets 22:44 Millions Stolen And First Victim 25:42 Estimate Fluff Red Flags 28:06 How the Scam Scales 29:16 Doorstep Trespass Story 33:06 Paying Before Completion 35:08 Payment Boundaries Retainage 39:39 Wire Fraud and Paper Trails 43:44 Five Contractor Scam Signs 50:56 Final Takeaways and Call In
Follow on Social Media: ________________ Love what you hear? | |||
| The Cost of Trust: Lessons from Homeowner Nightmares | 14 Apr 2026 | 00:57:37 | |
On the Chicks in Construction podcast, hosts Mikki Paradis and Jessica Abreu clarify that locking up a contractor’s tools is technically illegal despite past comments. Mikki shares her 200-pound dog Prime’s costly physical therapy and daily driveway walks. They then cover a Florida homeowner horror story involving a contractor operating under Environmental Kindness LLC (later Fortress Fencing Crew LLC) who botched retaining walls, French drains, sod, and fencing, demanded additional payments, caused property damage, and failed to fix issues; one homeowner paid $13,400 for faulty work and $35,000 to rebuild correctly, while another paid over $12,000 amid delays, missing scope items, mismatched materials, driveway and yard damage, and unprofessional behavior. The hosts warn that BBB is not a government bureau, stress getting multiple detailed bids, verifying licenses and insurance coverage for the specific scope, and researching contractors’ prior LLCs. 00:00 Contractor Accountability Rant 00:29 Podcast Intro and Legal Disclaimer 01:23 Tool Lockup Debate 02:38 Possession Proverb Myth 04:20 Prime Dog PT Costs 06:56 Spicy Comments and TikTok 10:59 Horror Story Setup Florida 17:19 BBB Ratings Reality Check 18:13 Retaining Wall Failure Details 23:23 New LLC Name Warning 23:46 Insurance Scope Lesson 26:39 Homeowner Lessons Learned 28:22 Deposits and Upfront Costs 29:10 Quote Seems Too Low 31:42 Delays and Surprise Add Ons 34:20 Incomplete Work and Extra Payment 36:28 Rock Delivery and Ghosting Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? 38:05 Property Damage and Excuses 46:38 Commercial vs Residential Chaos 52:16 How to Vet Contractors 57:30 Final Warnings and Wrap Up | |||
| Navigating Contractor Chaos: Homeowner Horror Stories | 08 Apr 2026 | 00:48:37 | |
Hosts Mikki Paradis and Jessica Abreu of Chicks in Construction share a North Carolina homeowner horror story: a bathroom gut remodel budgeted at $75,000 went off the rails after hiring “Marcus,” who quoted $15,000 labor and $30,000 materials, claimed a license wasn’t required under $40,000 labor, and urged the homeowner to pull permits. After multiple failed plumbing and waterproofing inspections, Marcus charged extra for “fixes,” then disappeared once confronted about licensing and insurance, leaving a gutted bathroom and defective work. A lawyer advised recovery was unlikely; a licensed contractor found additional code issues and quoted $31,500 to finish, bringing the final cost to $95,000 and the timeline to nine months. The hosts stress never paying for rework, verifying licenses and insurance, and treating homeowner-pulled permits and repeated inspection failures as red flags. 00:00 Never Pay for Rework
Follow on Social Media: ________________ Love what you hear? | |||
| From Digital Designs to Real Defects: Welcome Homes on Trial | 07 Apr 2026 | 01:01:57 | |
Hosts Mikki Paradis and Jessica Abreu of The Chicks in Construction discuss a homeowner horror story tied to alleged lawsuits against Welcome Homes, a PropTech startup founded in 2020 by DigitalOcean executives that promised custom homes built in about six months through an online design-and-build platform. Citing a vetted New York Post article, they describe claims of long delays, permit issues, construction errors (including flooded basements and hidden mistakes), and disputes over deposits and cancellation fees, including one couple who reportedly ended up with only cleared land and a pit. They note former HGTV host Anthony Carino joined as VP of Design but left in January 2024, saying leadership wouldn’t follow construction best practices, and that only one customer was living in a completed home when he left. The hosts highlight red flags like guaranteed timelines and inexperienced leadership, and advise homeowners to vet contractors carefully. 00:00 Experience Matters 00:27 Podcast Welcome 01:48 Pet Debate Begins 03:19 Cat Cafe Chaos 07:49 Allergy Aftermath 09:55 Babysitting Confessions 11:27 Water Cooler Horror 15:04 Legal Preface 16:13 Tech Meets Construction 19:58 Prefab Versus Hype 22:21 Six Month Promise 27:57 Welcome Homes Lawsuits 28:52 Price Too Good 29:57 Permits and Delays 31:04 Mud Pit Fallout 33:17 More Lawsuits Surface 35:14 HGTV Credibility Boost 40:16 Tech Bro Leadership 42:03 Business Model Pivot 48:27 Red Flags Checklist 55:57 Construction Is Hard 01:00:50 Final Takeaways Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Caught in the Fraud: A Tale of Deception in Construction | 31 Mar 2026 | 00:59:06 | |
Hosts Mikki Paradis and Jessica Abreu share a personal update about a car crashing through Mikki's fence and guardrail, then dive into a North Texas construction scandal involving Christopher and Raquel Judge of Judge DFW LLC. Marketing themselves on social media as a Chip-and-Joanna-style design-build team, they allegedly offered below-market bids, collected deposits and installment payments, and left more than 40 families with unfinished or poorly done projects across 24 jobs, totaling about $4.8 million in losses. Investigators found Christopher was not a licensed architect despite claiming to be and despite warnings from the Texas Board of Architectural Examiners. The case became federal due to wire fraud, large losses, and misrepresentation; both pled guilty, with potential prison time and restitution. The episode highlights key red flags and homeowner protections: verify licenses, avoid unusually low bids, use milestone-based payments, research history, and watch for communication breakdowns. 00:00 Contractor Scam Fallout 00:28 Podcast Intro and Format 01:06 Midnight Crash Story 04:50 Fence Damage and Insurance 09:00 Safety Concerns and Fix Ideas 15:04 Horror Story Setup 16:04 North Texas Fraud Case 21:37 Fake Architect Exposed 24:19 Scam Playbook Breakdown 25:15 Social Media and AI Fakes 26:59 Online Trust Collapse 27:48 Vetting Pros and Red Flags 30:34 Where the Money Went 31:14 Victims and Federal Case 34:50 Wire Fraud and Plea Deals 37:54 Restitution and No Money 42:15 Red Flags Checklist 51:06 Protect Yourself and Wrap Up | |||
| Avoid Scammers with this Homeowner Horror Story | 24 Mar 2026 | 00:54:36 | |
Hosts Mikki Paradis and Jessica Abreu of The Chicks in Construction share a South Carolina homeowner horror story about a long-saved kitchen remodel that went wrong after hiring a contractor who seemed confident and came recommended. The project suffered from missed schedules, constant add-on invoices, delays that stretched an 8–10 week timeline to nearly six months, and failed electrical inspections that required reopening finished walls. The homeowner later discovered the contractor wasn’t licensed and ended up researching codes, confirming inspection requirements, and managing ordering and scheduling herself. The hosts warn viewers to verify licenses and business status, ask about contingency plans, confirm permits, watch for scam-like pressure tactics, and never pay for rework caused by faulty work or failed inspections. 00:00 Contractor Liability Truth 00:19 Show Welcome and Mission 01:51 Subscribe and Support 02:19 Scam Calls and Tax Threats 07:57 Anti-Scam Safety Tips 09:51 South Carolina Horror Story Begins 12:20 Kitchen Reno Dream Setup 14:03 Red Flags and Disappearing Act 15:36 Contingency and Code Talk 19:54 Change Orders and Inspection Fails 26:00 Cabinet Price Hike Scam 27:29 Code Upgrades and Licensing 28:19 Feeling Trapped Mid-Reno 28:57 High-Pressure Scam Tactics 30:54 Budget Creep and Delays 32:45 Living Without a Kitchen 33:24 Inspections Reveal Bad Work 37:07 Never Pay for Rework 40:11 Unlicensed Contractor Shock 42:29 How Permits Get Pulled 46:35 Deep-Dive Contractor Vetting 53:49 Wrap-Up and Where to Find Us Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Say Goodbye to Home Warranties | 10 Mar 2026 | 00:59:14 | |
Mikki Paradis and Jessica Abreu break down why home warranties often fail homeowners: denial loopholes, code upgrade exclusions, long delays, and contractors you can’t choose. They share horror stories including a mismatched HVAC replacement that forced costly auxiliary heat and a technician caught going through a homeowner’s underwear drawer. Alternatives include thorough inspections, maintenance plans, and building a repair emergency fund. 00:00 Creepy Contractor Story 00:46 Podcast Intro and Outfit Talk 01:47 Home Builder Show Recap 02:53 Vegas Chaos and Temu Elmo 05:42 Sticker Shock at the Expo 07:20 Orlando Traffic Meltdown 09:04 Home Warranties Are a Scam 10:50 What Warranties Claim to Cover 13:16 How Claims Get Denied 17:05 Code Updates and Aging Loopholes 20:12 You Don’t Pick the Contractor 21:38 HVAC Horror Story Begins 25:44 Warranty HVAC Scam 28:01 Why Contractors Cut Corners 29:17 Claims Delays No Coverage 31:21 Not Insurance Arbitration 38:11 Are Warranties Ever Worth 43:43 Safety Risks Bad Techs 46:42 Smarter Alternatives Inspections 51:15 Emergency Fund Maintenance Plans 56:03 Final Takeaways Call To Action
Follow on Social Media: ________________ Love what you hear? | |||
| Bathroom Dreams to Nightmares: A Renovation Story | 03 Mar 2026 | 00:42:24 | |
In this episode of 'Chicks in Construction,' hosts Mikki Paradis and Jessica Abreu share a gripping homeowner horror story submitted by a listener. The episode details Amanda's journey of being scammed by an unlicensed contractor who left her with a gutted, half-finished bathroom and nearly $90,000 poorer. The hosts discuss the importance of contractor research, recognizing red flags, and the emotional and financial toll of such experiences. Tune in to learn valuable lessons in avoiding contractor scams and ensure your renovation projects stay on track. 00:00 Emotional Breakdown in the Bathroom
Follow on Social Media: ________________ Love what you hear? | |||
| Imagine Your Home Falling Apart | 24 Feb 2026 | 01:02:28 | |
In this episode of Chicks in Construction, Mikki Paradis and her co-host Jessica Abreu dive into a jaw-dropping homeowner horror story. The hosts discuss the shocking experience of Jake and his family, who moved into their dream home only to discover severe structural issues due to gross negligence by their contractor and the county inspections department. With foundation failures, code violations, and a battle to hold the builder accountable, this episode highlights the importance of due diligence, third-party inspections, and understanding the limitations of legal and insurance recourse in construction. Tune in for an eye-opening conversation on one of the worst-case scenarios in home construction. 00:00 Napkin Plans and Construction Realities 01:04 Welcome to Chicks in Construction 01:34 Super Bowl and Small Talk 03:50 Dog Tales and Special Trash 10:16 Homeowner Horror Story Introduction 13:08 The Chatham County Construction Nightmare 29:03 Builder Red Flags and Permitting Office Blunders 29:24 Accidental Email Exposes Structural Issues 30:35 Homeowner's Legal Battle Begins 32:33 Contractor's License Suspended and Fined 32:51 Licensing Board's Worst Code Violations Case 38:54 Homeowner's Insurance and Legal Struggles 45:16 Homeowner Recovery Fund Limitations 51:34 Advice for Future Homeowners 01:00:20 Closing Thoughts and Call to Action Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Mastering Communication in Construction: Tips from Nicole Fella | 17 Feb 2026 | 00:58:35 | |
In this episode of 'Chicks and Construction,' host Mikki Paradis, with co-hosts Jessica Abreu and special guest Nicole Fella, jump into the communication challenges that arise in construction projects. The episode highlights the importance of clear communication between homeowners, project managers, and contractors to achieve better outcomes and fewer disputes. Nicole shares her unique experience as an interior designer and general contractor, emphasizing the significance of setting clear expectations and understanding communication styles. The discussion covers practical advice for homeowners, including the necessity of asking questions and ensuring detailed, specific contracts. Listeners are encouraged to use tools like DISC survey to improve their communication understanding. The episode underscores that respectful and clear communication is essential for successful renovation projects. 00:00 Introduction to Communication in Construction 00:23 Meet the Hosts and Special Guest 01:30 Nicole's Background and Expertise 02:54 The Importance of Communication in Construction 04:31 Common Communication Pitfalls 06:33 Setting Clear Expectations 10:09 Effective Communication Strategies 14:24 Managing Client Expectations 17:06 Balancing Communication and Flexibility 19:51 Handling Communication Challenges 24:18 Establishing Reasonable Communication Expectations 28:23 The Stress of Late-Night Texts 28:43 Respectful Communication in Business 30:12 The Mosquito Service Incident 32:55 Handling Disrespectful Clients 38:16 The Importance of Clear Contracts 40:08 Advice for First-Time Renovators 44:28 Understanding Quotes and Allowances 52:25 The Value of Professionalism 53:41 Conclusion and Final Tips | |||
| Home Renovation Tips: Avoiding Mistakes and Celebrating Wins | 10 Feb 2026 | 00:48:01 | |
In this episode of The Chicks in Construction, hosts Mikki Paradis and Jessica Abreu discuss crucial red flags, do's and don'ts in the construction industry. Inspired by a serendipitous airplane chat, Mikki shares insights from a fellow passenger who had a positive experience building a dream home. The discussion emphasizes the importance of doing extensive research, hiring an independent interior designer, and avoiding bundled services with general contractors. They also encourage listeners to share both their construction horror stories and wins to help others navigate the complex world of home renovations and new builds. Catch all this and more as they dive deep into ways to ensure a smooth and successful construction project. 00:00 Introduction and Episode Inspiration 01:53 Purpose of the Podcast 03:25 Neighborhood Anecdotes and Real Estate Insights 10:04 Homeowner Wins and the Value of Interior Designers 21:29 The Value of Spending on Renovations 22:10 The Importance of Functionality in Home Design 22:42 Budgeting and Hiring for Home Renovations 24:44 The Role of Interior Designers 25:55 Avoiding Common Pitfalls in Home Renovations 32:25 Research and Contracts: Key to Successful Renovations 36:39 The Importance of Independent Professionals 44:08 Final Tips and Encouragement
Follow on Social Media: ________________ Love what you hear? | |||
| Built on Lies: A Tale of Homeowner Horror | 03 Feb 2026 | 00:47:35 | |
The Shocking Tale of a $300k Dream Home Scam | Chicks in Construction In this episode of The Chicks in Construction, hosts Mikki Paradis and Jessica Abreu dive into a devastating homeowner horror story in North Carolina where a homeowner's dream home project turned into a nightmare. After paying over $300,000, the homeowner was left with an unfinished lot and no house, due to a series of events involving shady contractors, deceitful actions, and unfulfilled promises. The hosts break down the red flags that were missed and provide vital advice for anyone considering building or remodeling their home. Tune in for detailed insights and tips on protecting yourself from fraudulent practices in the construction industry. 00:00 Introduction to a Homeowner's Nightmare 00:55 Meet the Hosts and the Story Unfolds 02:16 The Shocking Discovery 03:17 The Unraveling of a Scam 05:09 The Aftermath and Legal Loopholes 08:19 Lessons Learned and Final Thoughts 24:01 Uncovering Hidden Judgments 24:44 The Shady Tactics of a Fraudster 26:03 The Role of Licensing in Construction 30:41 The Importance of Research and Due Diligence 32:32 The Aftermath and Legal Struggles 38:34 Lessons Learned and Final Thoughts Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Tool Talk: Drill versus Impact Driver | 27 Jan 2026 | 00:43:39 | |
Welcome back to the Chicks in Construction! In this episode, hosts Mikki Paradis and Jessica Abreu kickstart their tool talk series - aiming to save you from buying unnecessary tools and helping you choose the ones that deserve a spot in your truck. They delve deep into the differences between power drills and impact drivers, offer tips for proper drywall anchoring, and share humorous anecdotes from their DIY experiences. Plus, they touch on New Year's words instead of resolutions and the importance of focusing and aligning goals. Tune in for an informative and entertaining session that blends practical advice with real-life stories! 00:00 Introduction to Tool Talk 00:30 Meet the Hosts: Mickey and Jessica 01:58 New Year Resolutions and Words of the Year 13:11 Tool Talk: Power Drills vs. Impact Drivers 20:56 The Best Stud Finder: Stud Buddy 21:36 Understanding Screws and Studs 24:16 Drill vs. Impact Driver: Key Differences 30:44 Choosing the Right Drywall Anchors 34:31 Tips for Using Drills and Anchors 40:54 Final Thoughts and Viewer Engagement | |||
| Kitchen Renovation Disasters: How to Spot Red Flags | 20 Jan 2026 | 00:56:02 | |
Kitchen Renovation Nightmare: Avoid These Costly Mistakes Welcome back to Chicks In Construction! In this episode, we dive into a gut-wrenching homeowner horror story involving a kitchen renovation gone terribly wrong. Hosts Mikki Paradis and Jessica Abreu discuss the dire consequences of hiring a contractor without checking licenses and permits, the importance of having a detailed contract, and why you should get multiple bids before starting your renovation. Learn valuable lessons about contingencies, budgeting, and how to avoid being taken advantage of in your home improvement projects. Plus, we address some spicy comments and provide tips for safeguarding your investment. Don't miss this eye-opening episode packed with essential advice for every homeowner looking to renovate. Like, subscribe, and share your own renovation stories in the comments! 00:00 Introduction and Podcast Overview 01:25 Food Delivery Shenanigans 06:00 Homeowner Horror Stories 12:22 The Importance of Checking Licenses 18:56 Breaking Down the Story 26:49 The Reality of Renovation Costs 28:04 Importance of Multiple Bids 28:19 Choosing the Right Contractor 38:16 Understanding Contingency Budgets 45:28 Permits and Inspections: Why They Matter 54:27 Final Thoughts and Viewer Engagement
Follow on Social Media: ________________ Love what you hear? | |||
| Dream Porch Fantasy - Homeowner Horror Story | 13 Jan 2026 | 00:50:48 | |
In this week's episode, Mikki and Jess dive into a homeowner's renovation journey that started with a dream of a cozy screened-in porch but quickly turned into an emotional rollercoaster. From weather delays to unexpected structural fixes, learn valuable tips on how to manage a small renovation project, understand the importance of permits, and handle change orders. If you're planning a home improvement project, this episode is a must-watch for keeping your dreams from turning into problems. Tune in for practical advice and a heartfelt homeowner experience! 00:00 A Dreamy Porch Vision 00:53 Meet the Hosts: Mickey and Jessica 01:44 New Year Resolutions and Vision Boards 02:45 The Power of Thumbs Down 11:12 Homeowner Horror Story Introduction 13:23 The Screened Porch Project Begins 24:57 The Unexpected Structural Fix 26:41 Permit Problems and Inspections 27:59 Dealing with Delays and Decisions 45:06 The Emotional Toll of Renovations 46:19 Lessons Learned and Final Thoughts 50:10 Conclusion and Call to Action Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Builder of the Year or Disaster of the Decade? A Homeowner's Horror Story | 06 Jan 2026 | 00:55:00 | |
Builder of the Year Disaster: Homeowner Horror Story In this episode of Chicks in Construction, hosts Mikki Paradis and Jessica Abreu dive into a startling homeowner horror story involving an award-winning 'Builder of the Year' who quickly turns into the 'Bumbler of the Decade.' From demolished heirloom gardens to an open house during a storm, the mishaps are beyond what any homeowner should endure. The episode also explores the importance of solid contracts, correct supervision, and clear communication in construction projects. Additionally, Mikki and Jessica add a light-hearted segment with a taste test of Shameless Snacks. Tune in for valuable construction insights, homeowner tips, and some much-needed laughs! 00:00 Builder of the Year Disaster 01:05 Meet the Hosts 01:32 New Year, New Us 01:55 Snack Time: Shameless Snacks Review 05:41 Book Recommendations 11:01 Homeowner Horror Story: The Builder of the Year 24:47 Communication Breakdown with Contractors 26:03 Permit Issues and Project Mismanagement 27:02 Emotional and Physical Damages 29:20 Insurance and Accountability 35:16 Contractual Obligations and Compensation 43:16 Ensuring Proper Supervision 52:16 Final Thoughts and Viewer Engagement Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| DIY Plumbing Disasters & Home Plumbing Tips - With Maribel Healy | 04 Nov 2025 | 01:06:06 | |
In this episode of 'Chicks in Construction,' hosts Mickey Paradise and Jessica welcome Maribel Healy from Benjamin Franklin Plumbing of the Triangle. They delve into various DIY plumbing disasters, common homeowner mistakes, and the importance of professional plumbing maintenance. From flooded kitchens to malfunctioning faucets, Maribel shares valuable tips on what homeowners should and shouldn't attempt on their own. Additionally, the discussion covers the benefits of a plumbing membership for maintaining fixtures and the surprising necessity of annual hot water heater flushes. Tune in for laughs, insights, and practical advice to prevent your home from turning into an indoor pool! 00:00 Introduction and Episode Overview 00:51 Meet the Hosts and Guest 02:14 How We Met: A Funny Story 06:26 Getting into Plumbing: Maribel's Journey 08:42 Homeowner Horror Stories 10:14 DIY Plumbing Disasters 12:47 The Importance of Knowing Your Water Shutoff 14:03 Shower Head Replacement Gone Wrong 23:25 The Faucet Fiasco 31:29 Spec Sheets and Mixing Parts 32:58 The Pretty Tax: Are Expensive Fixtures Worth It? 33:52 Exploring Popular Plumbing Brands 34:01 The Risks of Cheap Plumbing Fixtures 35:12 Toilet Troubles and Solutions 37:01 Special Trash and Parts Toilets 40:19 DIY Plumbing Cautionary Tales 43:38 Maintaining Your Water Heater 49:57 The Importance of Plumbing Inspections 01:02:08 Smart Plumbing Technology 01:04:39 Conclusion and Contact Information
www.benjaminfranklinplumbing.com/hollysprings-nc Call 919-999-3649, or visit our website using the book now button or on google clicking book now. Maribel Healy is the President and Owner of Benjamin Franklin Plumbing of the Triangle, proudly serving Cary, Apex, Holly Springs, Fuquay-Varina, and the surrounding communities. With nearly two decades in the trades, her journey began in her teens when a mentor recognized her potential and encouraged her to step into plumbing, setting the foundation for a career built on purpose, perseverance, and service. Under her leadership, Benjamin Franklin Plumbing has become known for both its dependable workmanship and its strong community presence. Her team organizes local food drives, sponsors area schools, and actively participates in multiple Chambers of Commerce, supporting local businesses and regional growth. Maribel leads with a servant’s heart guided by faith, integrity, and a genuine care for people. She lives, shops, and raises her children in the community she serves, investing daily in its growth while inspiring the next generation of women in the trades. Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Transform Your Dream Home: Expert Tips on Renovations with Chelsea Combs | 28 Oct 2025 | 00:44:09 | |
Have you ever fallen in love with a house only to fall out of love with its kitchen? Tune into this episode of The Chicks in Construction as hosts Mikki and Jess sit down with Chelsea Combs, owner of Green Hill General Contracting, to discuss transformative renovations that can turn any house into your dream home. Learn about renovation loans, realistic budgets, and avoiding construction chaos. Chelsea shares her insights on the importance of selecting the right general contractor, the significance of genuine reviews and licenses, and practical advice on making informed decisions for high return on investment renovations. Whether you own a home or are planning to buy one, Chelsea's expertise offers valuable guidance on optimizing your space. Plus, discover the inside scoop on why trusting your contractor and doing thorough research is crucial for a successful renovation project! 00:00 Falling in Love with Homes and Kitchens Link mentioned in the episode: https://linktr.ee/greenhillcontracting?fbclid=PAZXh0bgNhZW0CMTEAAaeXnsocBchKrsldIgh-9T15zRHHrtCxZ_D0HXM0mfK1fXVkaUe7UZmk3giXiQ_aem_ZMuojH2U6FKantQPjfRyjA Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Mastering Bathroom Renovations with Expert Nicole Fella | 21 Oct 2025 | 00:49:30 | |
Welcome back to the Chicks in Construction Podcast! In this episode, hosts Mikki and Jess dive into the world of bathroom renovations with special guest Nicole Fella, an experienced interior designer and licensed general contractor from North Carolina. Together, they explore essential pre-demolition steps, worthwhile splurges, and achieving a spa-like bathroom on a budget. They also discuss the importance of hiring licensed professionals, communicating accurately about project costs, and maintaining a good working relationship between contractors and clients. Don't miss Nicole's expert tips on creating timeless bathroom designs and navigating the renovation process smoothly. 00:00 Introduction and Podcast Welcome 00:58 Meet the Expert: Nicole Fella 03:01 The Real Cost of Renovations 05:37 In-House Team vs. Subcontractors 11:01 Client Horror Stories 17:50 Red Flags in Client-Contractor Relationships 24:39 Dealing with Past Traumas in New Relationships 25:18 Handling Difficult Clients and Payment Issues 28:25 Trusting the Process and Communication 29:30 Challenges with Inspections and Fair Season 31:14 Fair Experiences and Family Stories 35:07 Homeowner Tips and HGTV Myths 40:09 Timeless vs. Trendy Design Choices 42:48 Final Advice and Show Wrap-Up
With a dedication to excellence, Nicole pursued further qualifications and became a NASCLA Licensed General Contractor, demonstrating her commitment to mastering every aspect of the construction process. For over 11 years, she had been an integral part of The Bath Remodeling Center,LLC. where her talent and leadership have contributed significantly to the company’s success. Now, as the proud owner of The Bath Remodeling Center, LLC. (2024) Nicole brings her wealth of experience and creative vision to every project. With an unwavering commitment to customer satisfaction and a keen eye for detail, she leads her team in delivering exceptional results that exceed clients’ expectations. Since taking over ownership, The Bath Remodeling Center has been awarded Best Custom Home Builder/Home Renovation Specialist by Cary Magazine, and was recently featured in Architectural Digest. Nicole’s innovative approach to design, combined with her expertise in construction, allows her to transform ordinary spaces into extraordinary havens that reflect her clients’ unique tastes and lifestyles. Her dedication to quality craftsmanship and personalized service sets her apart in the industry, making her a trusted partner for those seeking to elevate their living spaces to new heights. Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Kitchen Renovation Nightmare | 14 Oct 2025 | 00:54:41 | |
In this episode of Chicks in Construction, hosts Miki & Jess share a spine-chilling story about a homeowner's kitchen renovation gone horribly wrong. Tackling issues from disappearing contractors to hazardous electrical work, they discuss the importance of hiring licensed contractors, securing permits, and getting inspections. Miki also delves into her upcoming travels, the challenges of family life during renovations, and the lessons learned from remodels gone awry. Tune in for expert advice, personal anecdotes, and tips to ensure your next renovation project doesn't turn into a nightmare! 00:00 A Dark and Stormy Renovation Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Expert Tips and Real-Life Stories of Home Organizers | 07 Oct 2025 | 01:00:27 | |
Welcome to another episode of Chicks in Construction! This episode goes deep into the transformative power of home organization. Joined by special guests Maria Butler of Clearly Organized and custom closet designer Sarah Tiani, the discussion highlights the benefits of hiring professional organizers. The hosts share personal stories, including Mickey’s journey through multiple organizers and the impact of finally finding the right fit. Discover how proper organization can save money, reduce stress, and even enhance your overall quality of life. Tips, insights, and real-life examples make this an episode you don’t want to miss. Tune in for expert advice on decluttering, effective organizing strategies, and when to consider professional help. Plus, get a sneak peek into high-end custom closets and practical solutions for everyday clutter. Don’t forget to like, subscribe, and visit our website for more homeowner horror stories!
00:52 Meet the Hosts and Guests 01:18 Mikki's Organizing Journey 05:04 The Importance of Hiring an Organizer 06:52 When to Consider Hiring an Organizer 11:15 Custom Closets and Office Designs 25:10 Common Organizing Mistakes 32:46 First Time Trying Caviar 33:05 Common Closet Misconceptions 33:20 Closet Pricing and Design Options 34:05 Luxury Closet Features 36:17 Organizing Tips and Collaborations 36:41 Container Store and Other Options 42:03 DIY vs Professional Organizing 46:26 The Emotional Impact of Organizing 50:02 The Benefits of an Organized Space 53:10 Hiring Professional Organizers 56:52 Conclusion and Contact Information
Follow on Social Media: ________________ Love what you hear? MORE ABOUT OUR GUEST: I am the owner of Clearly Organized. It has long been my dream to start my own business. I have always been a super-organized Monica type (Hello, Friends). As a family, we have moved 8 times, which helped me hone my organizing and staging skills. Thus was born Clearly Organized. I love the relationships we develop with our clients. We walk along beside you in your organizing journey, providing help and encouragement. I spent many years as an elementary school teacher and then a stay-at-home mom. I am married to my high school sweetheart and am a proud mom of two amazing boys. In my free time, I enjoy spending time with my family, soaking up the sun at the beach, and reading.
Stylish storage is self-care! I can create custom solutions to your storage challenges. Working in the triangle for 18 years. | |||
| Real Estate & Renovation: Insider Tips from Industry Expert - Lisa Houtman | 30 Sep 2025 | 00:57:12 | |
Welcome back to another episode of Chicks in Construction! In this episode, hosts Mikki and Jess dive into smart renovation decisions with their guest expert, Lisa Houtman from Houtman Home Realty and Heights Construction. Learn how to avoid common homeowner pitfalls and get insider tips on making renovations that actually add value to your home. From spotting red flags in real estate advice to understanding what upgrades are worth your time and money, this episode is packed with practical advice you won't want to miss. Plus, enjoy some fun banter about personal experiences and unique home improvement stories. Don't miss out—subscribe for more insightful and entertaining episodes! 00:00 Introduction to Smart Renovation Decisions Contact info for Lisa Houtman Lisa Houtman is the owner of Home Realty powered by Fathom Realty here in the Triangle and also part of her family company Heights Construction. Together they help homeowners looking to sell get their properties fixed up and sold. She came from a construction background has 10 years of experience in both commercial and residential combined, and when she moved to Raleigh 8 years ago, she started right in the residential trades in HVAC. From there, she worked her way up to Purchasing Manager for a local home builder before branching out into her own real estate and construction business. Today more than half of her business is new construction, so she has seen both sides: the builder’s perspective and the buyer’s perspective.
Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Fridge Scaping & DIY Disasters | 23 Sep 2025 | 00:46:36 | |
Welcome back to the Chicks in Construction! In this episode, our hosts dive into an exciting mix of leftover audience questions from their 'junk drawer,' explore the fascinating and wildly impractical trend of 'Fridge Scaping,' and share the do's and don'ts of DIY projects. They also cover when you really need a permit for home renovations and the challenges of living through a renovation. Tune in for heartfelt advice, hilarious anecdotes, and practical tips to navigate your construction and home improvement projects. Don't forget to subscribe, comment, and share your homeowner horror stories! 00:00 Welcome to Chicks in Construction
Follow on Social Media: ________________ Love what you hear? | |||
| Decoding Construction Gibberish: Terms You Never Knew You Needed! | 16 Sep 2025 | 00:52:18 | |
Welcome to The Chicks in Construction, the podcast where your hosts decode construction jargon and share laughter-filled stories. In this episode, we take a break from homeowner horror stories to discuss essential construction terms like change orders, submittals, punch lists, allowances, scope of work, and much more. Mickey and Jess humorously navigate through these terms, share personal anecdotes, and emphasize the importance of clarity in construction contracts. Tune in to learn and laugh as they offer invaluable tips for making your renovation projects smoother and more informed. 00:00 Welcome to The Chicks in Construction Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Bathroom DIY Disaster: Snowballing into a $26K Nightmare! | 09 Sep 2025 | 00:52:57 | |
Welcome back to the Chicks in Construction podcast! In this episode, we unravel a jaw-dropping homeowner horror story that started with a simple bathroom DIY and spiraled into a $26,000 catastrophe. Join us as we dive into the challenges, missteps, and unexpected expenses encountered during this renovation gone horribly wrong. From mold remediation to contractor woes, we share valuable lessons and tips to help you avoid the same pitfalls. Grab your hard hat and tune in for an entertaining and informative discussion that you won't want to miss! 00:00 Introduction to the Renovation Nightmare 00:48 Meet the Hosts: Mikki and Jess do the chitty chat 01:07 Small Talk and TikTok Trends 03:15 Dog Troubles and Vet Bills 08:22 Jessica's Busy Life with Kids and Softball 11:17 Homeowner Horror Story: The Moldy Bathroom 24:42 Wiring Woes and Bathroom Blues 25:57 Dog Drama and Family Tales 27:57 Tile Troubles and Contractor Chaos 30:03 The Costly Contractor Switch 33:11 Lessons Learned and Final Thoughts 49:08 Engage with Us! It's free! Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Building Your Dream Home: Insights from a General Contractor | Allison King | 02 Sep 2025 | 01:05:26 | |
In this episode of Chicks in Construction, host Mikki and guest-host Allison King discuss the challenges and triumphs of working with general contractors (GCs) on home building projects. Allison, from Clarity Design-Build, shares her journey from starting in sales to becoming a project manager, and highlights the importance of knowing what you want in a custom build. They delve into details about site conditions, allowances, and how to protect yourself financially during a construction project. Both hosts emphasize the importance of having everything in writing and controlling the finances to ensure the project's success. Whether you're considering building a custom home or renovating an existing one, this episode offers valuable insights to help you navigate the process smoothly. 00:00 Introduction to Chicks in Construction Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| We Bustin' 12 Common Construction Myths | 26 Aug 2025 | 00:57:07 | |
We debunk 12 common construction myths! From the truth about verbal agreements, exact project completion dates, and new construction home inspections, to whether higher prices always mean higher quality and the myth of being able to knock down any wall, Mikki and Jess have got you covered. They also share a personal project update, discuss the benefits of sourcing materials from local businesses, and dive into the complexities of contractor markups and insurance. Whether you're planning a renovation, building a new home, or just interested in the construction industry, this episode is packed with valuable insights and practical advice. Tune in and get the real scoop on these pervasive construction myths! 00:00 Introduction and Episode Overview Prism Paint + Design -You’re Triangle, Triad, Piedmont Benjamin Dealer Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Nightmare Renovation in North Raleigh: Importance of Licensed Contractors & Permits | 19 Aug 2025 | 00:51:47 | |
In this episode of Chicks in Construction, hosts Mikki and Jess dive into a harrowing North Raleigh renovation story that underscores the importance of hiring licensed general contractors, obtaining permits, and not prepaying large sums of money upfront. They highlight a homeowner's ordeal with a fraudulent GC who left numerous structural and compliance issues unchecked, leading to significant financial and emotional stress. Tune in to learn vital tips on how to protect yourself in construction projects and ensure your renovations don't turn into a nightmare. 00:00 Introduction and Episode Overview ________________ Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| The Four-Week Bathroom Project That Took Four Months | 12 Aug 2025 | 00:42:37 | |
What was supposed to be a clean, modern upgrade to the only full bathroom in a 1960s split-level turned into four months of dust, delays, and constant headaches. With a solid budget and a contractor who promised four to five weeks, this Rhode Island homeowner thought they were in good hands. Instead, they found themselves showering in a freezing basement with a garden hose while bills kept piling up. Mikki and Jess walk through every misstep, from shoddy plumbing to crooked tile, and the money decisions that made a bad situation even worse. This story is not just about a failed bathroom reno, it is a cautionary tale about what happens when you lose control of your project’s budget and timeline. Inside the Homeowner Horror Story:
If you are about to hire a contractor, this is your sign to protect your money, pay for completed work only, and never assume that will not happen to you. ________________ Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| How to Spot a Real Painter vs. Someone Who Just Bought a Paintbrush | 05 Aug 2025 | 01:04:20 | |
Most painters are disasters waiting to happen. They'll destroy your floors, paint over problems instead of fixing them, take your deposit and disappear for weeks, then leave you with a mess that looks worse than when they started. But how do you spot the difference between a real professional and some guy who thinks painting is easy money? Elizabeth Mejía from Top Empire Painting has seen it all, from painters who literally paint over staples sticking out of trim to clients who lock contractors out mid-job and hurl racial slurs. She breaks down the warning signs, red flags, and insider secrets that separate legitimate pros from the disasters that give the industry a bad name. What You'll Learn:
This is your complete insider guide to hiring a painter who won't ruin your house, steal your money, or make you want to burn everything down. Connect with Top Empire Painting: ________________ Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Reasonable vs. Unreasonable Renovation Expectations | 29 Jul 2025 | 01:02:23 | |
Mikki and Jess tackle one of the biggest problems in home renovations: homeowners going in completely unprepared for what construction actually looks like. After seeing so many horror stories from listeners, they realized many of the "disasters" could have been avoided if people just knew what was normal versus what was actually worth getting upset about. They delve into common challenges faced during renovations, emphasizing the importance of hiring skilled professionals, anticipating delays, and effective communication with contractors. They also cover the necessity of having a contingency budget and understanding the true costs and processes involved in renovations. The episode highlights the need for realistic expectations to ensure a smoother renovation experience, sharing both homeowner and contractor perspectives on common pitfalls and best practices. In this episode, you’ll hear about:
________________ Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Insurance Claims Decoded with Public Adjuster Nicolle Bochenski | 22 Jul 2025 | 00:45:46 | |
When your roof leaks, a pipe bursts, or a tree crashes through your house, your first instinct is to call your insurance company. But one wrong word in that conversation can mean the difference between getting fully covered or getting nothing at all. Most homeowners don’t realize how much hinges on the language they use...until their claim is denied. In this episode, Mikki sits down with Nicolle Bochenski of Precision Public Adjusting to expose how often claims are unfairly denied, and what you can do about it. From roof damage to total home losses, Nicolle breaks down the red flags, policy loopholes, and rights most homeowners don’t know they have. In this episode, you’ll hear about:
Connect with Precision Public Adjusting: ________________ Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| Top Renovation Budget Tips to Avoid Costly Surprises | 15 Jul 2025 | 01:13:17 | |
Ever wondered what your renovation should cost? In this episode of The Chicks in Construction, Mikki and Jess get real about renovation budget tips that can save your wallet and your sanity. Whether you're upgrading your forever home or prepping a property for Airbnb, this episode is packed with practical advice that every homeowner needs to hear. In this episode, you’ll hear about:
Mentioned In The Episode: HomeAdvisor Cost Estimator Tool: https://www.homeadvisor.com/cost/ ________________ Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| The Facebook Roofer Who Ghosted and Left Them Soaked | 08 Jul 2025 | 00:45:41 | |
After a spring storm, a brown stain appeared in the ceiling. A quick fix felt doable until the roofer vanished, the drywall collapsed, and the insurance company refused to help. What started as one drip turned into a financial gut punch. In this episode, Mikki and Jess unpack every moment of a roof fix gone sideways. From the first red flag to the final invoice, they break down what this homeowner thought he was doing right and how it all went wrong. Inside the Homeowner Horror Story:
Mentioned In The Episode: Need a website built? Check out www.yourwpguy.com and use code MIKKI10 for 10% off. ________________ Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| The Mold Scare Tactics Homeowners Fall For with Danyelle Holland | 01 Jul 2025 | 00:44:49 | |
Mold feels like a silent menace; one whiff of “You’ll need to gut the house” and your budget evaporates. In this episode, Mikki sits down with Danyelle Holland of Atlantic Corp to expose the fear-based sales pitches that can turn a routine remediation into a five-figure panic. When a cough, a crawl-space puddle, or a mysterious odor sends you running to Google, you can end up paying for fixes you never needed. Danyelle explains exactly how real pros separate fact from fright, and why the right certifications matter more than any shiny brochure. Inside the Episode
Resource: Certifications to Look For
If scare-heavy salespeople are circling, listen first and save your wallet. Connect with this episode's expert: atlanticmoldexperts.com ________________ Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||
| The $2,000-a-Hole Window Myth with Ashley Selzer | 24 Jun 2025 | 01:29:44 | |
Everyone’s heard it: “A quality replacement window should run you two grand per opening, or you’re buying junk.” That pitch (often delivered after hours of kitchen-table arm-twisting) convinces too many homeowners to sign for triple-pane glass and monster price tags they don’t actually need. Mikki’s latest guest, licensed GC Ashley Seltzer of Wallaby Windows, dismantles that narrative, along with the pushy sales tactics behind it, one NFRC label at a time. Ashley explains how quotes balloon, why “energy-efficiency” buzzwords get abused, and the questions that separate a real consultative pro from a chuck-in-a-truck. From deposit math to pocket-vs-full-frame installs, she gives listeners a playbook for sane pricing and sound decisions. Inside the Episode:
When a window quote tops your last roof bid, hit pause; these insights might save you five figures and a lot of shattered expectations. Connect with this episode's expert: ________________ Submit your homeowner horror story: Follow on Social Media: ________________ Love what you hear? | |||